Terms and Conditions

Wayne Morgan Construction

Last Updated: April 8, 2026

Welcome to Wayne Morgan Construction! We’re glad you’re here. These Terms and Conditions (“Terms”) govern your use of our website located at [Insert the Website Site] (the “Site”) and your engagement with our services. By accessing our Site, requesting a quote, or working with us on a project, you agree to these Terms. If you don’t agree, please don’t use our Site or services.

At Wayne Morgan Construction, we build dreams at affordable prices, and we want your experience with us to be clear, fair, and straightforward. These Terms explain the rules of the road for both of us. Please read them carefully.

 

1. Acceptance of Terms

By browsing our website, submitting a contact form, requesting an estimate, or entering into a service agreement with Wayne Morgan Construction (“Company,” “we,” “us,” or “our”), you confirm that you are at least 18 years old, have the legal authority to enter into agreements, and accept these Terms in full. If you are acting on behalf of a business or organization, you represent that you have the authority to bind that entity to these Terms.

These Terms apply to all visitors, users, and others who access or use the Site. We reserve the right to update or modify these Terms at any time without prior notice. Your continued use of the Site after any changes constitutes acceptance of the new Terms. We encourage you to review this page periodically for updates.

 

2. About Our Services

Wayne Morgan Construction, based in Douglasville, Georgia, has been proudly serving the west side of Atlanta since March 10, 1973. We specialize in:

  • New custom home building
  • Major home remodeling and renovations
  • Decks, porches, and outdoor living spaces
  • Electrical installations and upgrades
  • Welding and metal fabrication
  • Custom millwork, trim, cabinetry, windows, doors, and stairs
  • Design-build project management

Our Promise: Quality work at reasonable prices. Unlike many contractors, we do our own work; we don’t subcontract. This means the skilled craftspeople you meet during your estimate are the same team who will build your project. This approach ensures consistency, accountability, and the personal touch that comes from decades of experience.

All services are provided based on a written agreement or contract. Estimates provided via our website, email, or phone are preliminary and subject to final assessment, scope confirmation, and a signed contract. No project begins without mutual agreement on scope, timeline, and pricing.

 

3. Use of Our Website

3.1 Permitted Use

You may use our Site for personal, non-commercial purposes, including:

  • Learning about our services and past projects
  • Viewing our photo gallery and portfolio
  • Contacting us via forms, email, or phone
  • Requesting estimates or consultations

3.2 Prohibited Activities

You agree not to:

  • Use the Site for any unlawful purpose or in violation of local, state, or federal laws
  • Attempt to interfere with, disrupt, or overload the Site’s functionality
  • Scrape, copy, or reproduce content without written permission
  • Submit false, misleading, or fraudulent information in forms or communications
  • Use automated systems (bots, scripts) to access the Site

3.3 Account Security

If we offer user accounts in the future, you are responsible for maintaining the confidentiality of your login credentials and for all activities under your account. Notify us immediately of any unauthorized use.

 

4. Intellectual Property

All content on this Site, including text, graphics, logos, images, photos, videos, project portfolios, and software, is the property of Wayne Morgan Construction or its content suppliers and is protected by U.S. and international copyright, trademark, and other intellectual property laws.

You may view, download, or print content from the Site solely for your personal, non-commercial use in connection with evaluating or engaging our services. You may not:

  • Republish, sell, rent, or sub-license material from the Site
  • Redistribute content from our Site (except where specifically allowed)
  • Use our name, logo, or project images for commercial purposes without written consent

Project photos and testimonials are used with client permission. If you believe any content infringes your rights, please contact us with details, and we will review your claim promptly.

 

5. Estimates, Contracts, and Project Agreements

5.1 Preliminary Estimates

Estimates provided via our website contact forms, email, or phone consultations are non-binding and for informational purposes only. Final pricing requires an on-site assessment, detailed scope review, material selections, and a written contract.

5.2 Written Contracts Required

All projects proceed under a written agreement that outlines:

  • Scope of work and specifications
  • Materials, finishes, and allowances
  • Project timeline and milestones
  • Payment schedule and terms
  • Warranty information
  • Change order procedures
  • Responsibilities for permits, inspections, and site access

No work begins until both parties sign a contract. Verbal agreements are not binding.

5.3 Change Orders

Changes to the original scope after contract signing require a written change order, signed by both parties, detailing adjustments to cost, timeline, or materials. Work on changes will not proceed until the change order is approved.

 

6. Payment Terms

  • Deposits: A deposit may be required to secure materials and schedule your project. Deposit amounts vary by project scope and are specified in your contract.
  • Progress Payments: For larger projects, payments may be scheduled at defined milestones (e.g., foundation complete, framing complete). Invoices are due within 15 days unless otherwise agreed.
  • Final Payment: Final payment is due upon project completion, final walkthrough, and client acceptance. A lien waiver will be provided upon receipt of final payment.
  • Payment Methods: We accept checks, bank transfers, and major credit cards (processing fees may apply).
  • Late Payments: Unpaid balances may incur interest at 1.5% per month (18% APR) or the maximum rate allowed by Georgia law. Work may be paused for non-payment per contract terms.

All prices are in U.S. dollars and subject to change until a contract is signed. Estimates do not include unforeseen conditions (e.g., structural issues discovered during demolition), which will be addressed via change order.

 

7. Permits, Inspections, and Compliance

For most construction projects, permits and inspections are required by local authorities. Unless otherwise specified in your contract:

  • Wayne Morgan Construction will typically handle permit applications and coordinate inspections on your behalf.
  • Permit fees and inspection costs are the client’s responsibility and will be included in your estimate or billed as incurred.
  • You agree to provide necessary documentation (e.g., property surveys, HOA approvals) in a timely manner.
  • You are responsible for ensuring your project complies with homeowner association (HOA) rules, zoning laws, and deed restrictions. We advise consulting your HOA or local planning office early in the design process.

We build to meet or exceed Georgia state and local building codes. However, code interpretations can vary by jurisdiction. Final approval rests with the local building official.

 

8. Warranties and Guarantees

8.1 Workmanship Warranty

Wayne Morgan Construction warrants that our work will be performed in a professional and workmanlike manner, consistent with industry standards. We provide a one-year warranty on workmanship from the date of project completion, covering defects directly resulting from our installation or construction methods.

8.2 Manufacturer Warranties

Materials, appliances, windows, roofing, and other products carry warranties from their manufacturers. We will provide applicable warranty documentation upon request. Claims for product defects must be directed to the manufacturer; we will assist with coordination where reasonable.

8.3 Exclusions

Warranties do not cover:

  • Damage from normal wear and tear, accidents, neglect, or improper maintenance
  • Issues arising from client-provided materials or third-party work
  • Problems caused by acts of nature (storms, floods, earthquakes), pests, or soil movement
  • Cosmetic changes due to aging, settling, or environmental factors

To make a warranty claim, contact us in writing with photos and a description of the issue. We will assess and respond within a reasonable timeframe.

 

9. Limitation of Liability

To the fullest extent permitted by Georgia law:

  • Wayne Morgan Construction shall not be liable for any indirect, incidental, special, or consequential damages arising from your use of our Site or services, including loss of profits, data, or business opportunities.
  • Our total liability for any claim related to our services shall not exceed the total amount paid by you under the specific contract giving rise to the claim.
  • We are not responsible for delays or failures due to causes beyond our reasonable control, including weather, material shortages, labor disputes, permit delays, or acts of God.

You acknowledge that construction involves inherent variables. While we commit to quality and communication, unforeseen conditions may arise. We will notify you promptly and propose solutions, but we cannot guarantee outcomes beyond our agreed scope and professional standards.

 

10. Disclaimers

10.1 Site Content

Our website content is for general informational purposes only. Project photos represent past work; results may vary based on site conditions, materials, and design choices. We strive for accuracy but do not warrant that Site content is error-free, complete, or current.

10.2 No Professional Advice

Information on our Site does not constitute legal, engineering, or architectural advice. For structural, zoning, or design questions beyond our scope, we recommend consulting licensed professionals.

10.3 Third-Party Links

Our Site may link to third-party websites (e.g., material suppliers, design inspiration). We do not endorse or control these sites and are not responsible for their content, privacy practices, or availability. Accessing external links is at your own risk.

 

11. Privacy and Data Use

Your privacy matters to us. When you contact us via our website forms, email, or phone, we collect information such as your name, contact details, project description, and property address. This information is used solely to:

  • Respond to your inquiries
  • Prepare estimates and proposals
  • Manage projects and communication
  • Send service-related updates (with your consent)

We do not sell, rent, or share your personal information with third parties except as required to complete your project (e.g., ordering materials) or comply with legal obligations. For full details, please review our separate [Privacy Policy].

By submitting information, you consent to us storing and using it for business purposes as described above. You may request deletion of your data at any time, subject to legal record-keeping requirements.

 

12. Client Responsibilities

To ensure a smooth project, you agree to:

  • Provide accurate, complete information during consultations and in contracts
  • Secure necessary HOA approvals, easements, or neighbor agreements before work begins
  • Ensure safe, clear access to the worksite (removing vehicles, pets, valuables)
  • Make timely decisions on selections, approvals, and change orders to avoid delays
  • Maintain insurance on your property (we carry liability and workers’ compensation insurance for our team)
  • Communicate concerns promptly through agreed channels

Delays caused by client decisions, access issues, or unforeseen site conditions may adjust the project timeline. We will keep you informed and work collaboratively to minimize disruptions.

 

13. Dispute Resolution

We believe in solving problems through open communication. If a dispute arises:

  1. Direct Discussion: Contact Wayne Morgan directly to discuss the issue. Most concerns are resolved quickly through conversation.
  2. Mediation: If unresolved, both parties agree to attempt mediation with a neutral third party in Douglas County, Georgia, before pursuing litigation.
  3. Governing Law: These Terms and any disputes shall be governed by the laws of the State of Georgia, without regard to conflict of law principles.
  4. Venue: Any legal action shall be filed in the state or federal courts located in Douglas County, Georgia.

You waive any objection to venue or forum non conveniens in these courts. This clause does not prevent either party from seeking injunctive relief for intellectual property or confidentiality breaches.

 

14. Termination

14.1 By Client

You may terminate a project per the terms of your written contract, which typically includes provisions for cancellation fees based on work completed and materials ordered.

14.2 By Company

We reserve the right to suspend or terminate services if:

  • You breach contract terms (e.g., non-payment, unsafe site conditions)
  • You provide false information or engage in fraudulent activity
  • Circumstances make project completion impractical or unsafe

Upon termination, you remain responsible for payment for work completed and non-cancelable expenses incurred.

 

15. Modifications to Terms

We may update these Terms periodically to reflect changes in our services, legal requirements, or business practices. Updates will be posted on this page with a revised “April 8, 2026” date. Your continued use of the Site or services after changes take effect constitutes acceptance. For material changes affecting active contracts, we will notify you directly.

 

16. Severability and Entire Agreement

If any provision of these Terms is found unenforceable by a court of competent jurisdiction, the remaining provisions will remain in full force and effect. These Terms, together with your signed contract and any written change orders, constitute the entire agreement between you and Wayne Morgan Construction regarding the subject matter and supersede all prior discussions or representations.

No waiver of any Term is effective unless in writing and signed by an authorized representative. Our failure to enforce any right or provision does not constitute a waiver of future enforcement.

 

17. Contact Us

Have questions about these Terms or ready to start your project? We’re here to help.

Wayne Morgan Construction

Douglasville, Georgia

Email: [Your Email Address]

Phone: [Your Phone Number]

Website: [Insert the Website Link]

For legal notices regarding these Terms, please email with “Legal Notice” in the subject line.

18. Final Thoughts

At Wayne Morgan Construction, we’ve been building homes and relationships on the west side of Atlanta since 1973. We keep things simple: quality work at reasonable prices, done by our own skilled team, no subcontractors. When you choose us, you’re choosing experience, accountability, and a partner who cares about bringing your vision to life.

These Terms exist to protect both of us and ensure clarity as we work together. We believe that trust is built on transparency, so if anything here is unclear, just ask. We’re always happy to talk through details.

We build dreams at affordable prices, and we’d love to help you build yours.

Thank you for considering Wayne Morgan Construction. Let’s create something great together.